The General Contractor Subcontractor Agreement is a fundamental document in U.S. construction projects where specialized work needs to be delegated to qualified subcontractors. It is used when a general contractor needs to engage specific trade contractors or specialized service providers to complete portions of a larger construction project. The agreement ensures compliance with federal and state construction laws while protecting both parties' interests through detailed specifications of work scope, payment terms, insurance requirements, and risk allocation. This document is particularly critical in modern construction projects where complex work requires multiple specialized subcontractors, each needing clear contractual guidelines and protection. It helps maintain project coordination, quality standards, and regulatory compliance while providing legal recourse in case of disputes.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the General Contractor and Subcontractor, including legal names, addresses, and registration numbers
2. Background: Context of the agreement, including reference to the main construction project and prime contract
3. Definitions: Key terms used throughout the agreement, including technical and legal terminology
4. Scope of Work: Detailed description of the subcontractor's responsibilities, deliverables, and performance standards
5. Contract Price and Payment Terms: Compensation details, payment schedule, retention amounts, and invoicing procedures
6. Project Timeline: Start date, completion date, milestones, and schedule requirements
7. Performance Standards: Quality requirements, workmanship standards, and compliance with codes and regulations
8. Insurance Requirements: Required insurance coverage types and limits, including liability and workers' compensation
9. Indemnification: Mutual protection against claims, damages, and losses
10. Warranties: Guarantees of work quality, materials, and performance
11. Safety Requirements: Safety protocols, OSHA compliance, and site safety responsibilities
12. Default and Termination: Conditions for default, cure periods, and termination procedures
13. Dispute ReĂÜĚŇÖ±˛Ą: Process for handling disagreements, including mediation and arbitration procedures
14. General Provisions: Standard legal clauses including notices, assignment, and governing law
1. Bond Requirements: Include when performance or payment bonds are required for the project
2. Environmental Compliance: Add for projects with specific environmental requirements or concerns
3. Hazardous Materials: Include when the work involves handling or exposure to hazardous materials
4. Union Requirements: Add when the project involves union labor or collective bargaining agreements
5. Equipment and Materials: Include when specific equipment or materials are to be provided by either party
6. Storage and Staging: Add when specific requirements exist for material storage and work staging areas
7. Testing and Inspection: Include when specific testing protocols or third-party inspections are required
8. Liquidated Damages: Add when specific monetary penalties for delays or non-performance are needed
9. Force Majeure: Include detailed force majeure provisions for projects in high-risk areas or with critical timelines
1. Schedule A - Scope of Work: Detailed technical specifications and drawings for the subcontractor's work
2. Schedule B - Price Breakdown: Itemized pricing, unit rates, and payment schedule
3. Schedule C - Project Schedule: Detailed timeline with milestones, dependencies, and critical path activities
4. Schedule D - Required Insurance: Specific insurance requirements, coverage limits, and additional insured parties
5. Schedule E - Quality Control Plan: Specific quality control procedures, testing requirements, and acceptance criteria
6. Schedule F - Safety Plan: Project-specific safety requirements and procedures
7. Schedule G - Required Forms: Templates for progress reports, payment applications, and change orders
8. Appendix 1 - Project Drawings: Relevant architectural and engineering drawings
9. Appendix 2 - Technical Specifications: Detailed material and installation specifications
10. Appendix 3 - Site Rules: Site-specific regulations, access procedures, and working hours
Find the exact document you need
General Contractor And Subcontractor Agreement
U.S.-governed agreement between general contractor and subcontractor defining work scope, terms, and obligations in construction projects.
Download
General Contractor Contract With Subcontractor
U.S.-governed construction agreement between general contractor and subcontractor defining work scope, terms, and responsibilities.
Download
Standard Contractors Agreement
A legally binding U.S. agreement that establishes terms between a business and an independent contractor, ensuring compliance with federal and state regulations.
Download
Contract Agreement Between Owner And Contractor
A U.S. legal agreement defining terms and conditions between a property owner and construction contractor for building work.
Download
Home Contractor Agreement
A U.S. legal agreement between a homeowner and contractor defining terms for residential construction or renovation work.
Download
Contractor Warranty Agreement
A U.S.-compliant legal agreement defining a contractor's warranty terms and obligations for construction work or improvements.
Download
Collaboration Agreement With Builder
A U.S.-based legal agreement establishing terms and conditions between property owners/developers and builders for collaborative construction projects.
Download
Building Material Contract Agreement
A U.S.-governed agreement establishing terms for the supply of construction materials, including specifications, pricing, and delivery terms.
Download
Contractor Owner Agreement
A U.S.-governed legal agreement between a property owner and contractor defining project terms, responsibilities, and obligations.
Download
Agreement Between Two Parties For Construction Contract
A U.S.-governed bilateral construction contract defining project scope, terms, and obligations between property owner and contractor.
Download
Pre Construction Purchase Agreement
A U.S.-governed agreement for purchasing property before construction completion, outlining terms between buyer and developer.
Download
Agreement Between Builder And Contractor
A U.S.-governed contract defining the terms and conditions between a builder and contractor for construction services.
Download
New Construction Purchase Agreement
A U.S. legal agreement governing the purchase of newly constructed property, outlining terms between builder and buyer.
Download
Home Improvement Construction Contract
A U.S.-compliant contract between property owner and contractor for home improvement projects, outlining work scope, terms, and obligations.
Download
Collaboration Agreement For Construction Of Building
A U.S.-governed agreement establishing terms for multiple parties collaborating on a construction project.
Download
Construction Operating Agreement
A U.S.-governed legal agreement establishing terms and conditions for construction operations, including safety protocols and operational procedures.
Download
Construction Company Contracts
A U.S.-governed construction contract establishing terms, conditions, and obligations for construction projects, compliant with federal and state regulations.
Download
General Contractor Subcontractor Agreement
U.S.-governed agreement between general contractor and subcontractor defining work scope, payments, and responsibilities in construction projects.
Download
Landscape Contractor Contract
A U.S.-governed contract defining terms between landscape contractors and property owners for landscaping services and maintenance.
Download
Subcontract Agreement For Construction Work
A U.S.-governed agreement between contractor and subcontractor defining terms, conditions, and responsibilities for specified construction work performance.
Download
Owner Subcontractor Agreement
A U.S. legal agreement between property owner and subcontractor defining work scope, terms, and obligations under federal and state construction laws.
Download
Contract Between Builder And Client
A U.S.-governed contract establishing terms between a builder and client for construction services.
Download
Building Construction Contract Agreement
A U.S.-governed legal agreement between property owners and contractors defining terms and conditions for construction projects.
Download
Agreement Between Two Contractors
A U.S. legal agreement establishing terms and conditions between two independent contractors for collaborative work or services.
Download
Design And Construct Contract
A US-governed contract combining design and construction services under a single agreement between owner and design-build contractor.
Download
Design Build Contract
A U.S.-governed contract combining design and construction services under a single agreement, establishing responsibilities and requirements for integrated project delivery.
Download
Construction Labor Contract Agreement
A U.S.-compliant legal agreement establishing employment terms between construction contractors and workers, covering work scope, compensation, and safety requirements.
Download
Construction Collaboration Agreement
A U.S.-compliant legal agreement establishing terms for multiple parties to collaborate on a construction project.
Download
Agreement Between Land Owner And Builder
A U.S.-governed contract establishing terms between a land owner and builder for construction work on specified property.
Download
Letter Of Agreement For Construction Work
A U.S.-compliant legal document establishing terms between contractor and property owner for construction services.
Download
Management Building Contract
A U.S.-compliant legal agreement between property owner and construction manager defining project management services and responsibilities.
Download
Construction Work Agreement
A U.S.-governed legal agreement between a contractor and property owner establishing terms for construction services.
Download
Commercial Construction Agreement
A U.S.-governed contract between owner and contractor establishing terms for commercial construction projects.
Download
Owner Builder Agreement
A U.S. legal agreement establishing terms and conditions for property owners acting as their own general contractor in construction projects.
Download
General Contractor Contract With Owner
A U.S. construction contract between property owner and general contractor defining project terms, responsibilities, and obligations.
Download
Construction Labor Agreement
A U.S.-governed agreement establishing employment terms between construction contractors and workers, covering wages, hours, and working conditions.
Download
Home Builder Contract
A U.S.-compliant legal agreement between a builder and property owner for new home construction, specifying terms, conditions, and obligations.
Download
Building Construction Agreement
A U.S.-governed contract between property owner and contractor establishing terms for building construction projects.
Download
Builder Agreement
A U.S.-compliant legal agreement between a builder and property owner defining construction project terms and responsibilities.
Download
Residential Construction Contract
A U.S.-governed legal agreement between property owner and contractor for residential construction or renovation projects.
Download
łŇ±đ˛Ôľ±±đ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; łŇ±đ˛Ôľ±±đ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it